Building Agreement 1 Party A (full name): (hereinafter referred to as Party A)
Party B (full name): (hereinafter referred to as Party B)
Party A: Party B: According to the Building Law, Economic Contract Law and other relevant laws and regulations, in order to standardize the construction, Party A and Party B reached an agreement on the construction of private houses on the principles of equality, voluntariness, fairness, reasonableness and mutual benefit through consultation.
1. For the agreement on building (the same agreement), the compensation for the old house will be paid with the change, and it will not exceed two years at the latest (the deadline is 20xx65438+the end of February, and it must be paid in one lump sum regardless of whether the old house is changed or not).
2. Zhang Jingguo selected the third bid section to obtain the fourth floor of a new house in this agreement, and another 20,000 yuan was used to compensate Party A, and the compensation was paid in one lump sum from the date of occupancy or resale, not exceeding two years at the latest, so as to smoothly start the new rural housing construction for the third child, Zhang Jinghua. And in order to solve the problems between brothers (the deadline is 20xx65438+the end of February, both living and selling must be paid in one lump sum). In addition, based on the principle of fairness and justice, the three brothers (eldest brother Jingren Zhang is not represented by his son Zhang Wei, and it is clear that the contractor will turn the fourth floor into the same floor as the lower floor, and Zhang Jingguo must take the second son Zhang Jingguo and the fourth son Zhang Jinghong) to negotiate and solve the problem, and the new house and the old house will be merged into one, and Zhang Wei, the contractor, will be given 30,000 yuan as the activity fund. Otherwise, the supplementary explanation is unsuccessful.
Bid allocation, 1 bid is responsible for the construction of new houses, bid 2 is responsible for the renovation of old houses, and bid 3 is responsible for living in new houses. If you can add a story on the fourth floor, it is agreed that the three parties will share it and live on any fourth floor on the fourth floor, and an uncle will choose any one of them to complete it.
No one has the right to interfere.
1. Zhang jinghua is Party A, and the contractor of 1 bid section is Party B, and Party A will not undertake any work during the construction period. This agreement is made in quadruplicate, including the expenses and responsibilities of Jingren Zhang, the eldest son, his wife and children, and the expenses and responsibilities of either party after the success of the new house (directly living on the first floor and the front garage).
The three uncles and nephews must share this burden (Note that Zhang Jinghua and the other two candidates must give up the old house. 5. This agreement shall come into effect as of the date of signing, and the above-mentioned householder and team leader members plus the old table Li have the right).
Dahua and others signed it as evidence.
Second, the responsibilities and obligations for the winning result are as follows:
Finally, add a special point. When paying compensation to Party A, the agents of the three parties to this agreement must be present.
1, Zhang Wei chooses 1 as the contractor. During the construction period, the quality should reach the standard, and the safety responsibility should be witnessed by itself.
No one else will be responsible for this. There are two garages on the first floor of the house, and the back garage and the second and third floors are handled by themselves. The first floor is responsible for water, electricity, doors and windows, anti-theft net, and the water and electricity on the fourth floor are in place according to the market sales model. In addition, Party A shall be compensated 40,000 yuan, and the compensation shall be paid in one lump sum after the house is sold, and it shall not exceed two years at the latest (20xx 65438+).
2. Zhang Jinghong chose the second bid section to be responsible for the renovation of two old houses, and took another 40,000 yuan as compensation.
Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Head of household: _ _ _ _ _ _ _ _ _ _ _
Signed on xx, xx, XX
Part II of the Building Agreement Seller (Party A):
Name: ID number: _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Buyer (Party B):
Name: ID number: _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, on the basis of equality, voluntariness, honesty and credit, Party A and Party B reach the following agreement on the purchase of the house by Party B from Party A:
Article 1 Party A voluntarily sells a legally acquired house under construction to Party B.. The structure of the house is, the nature of the house is, and the construction area is square meters (subject to the actual area, not less than square meters). And ensure that the consent of other property owners or interested parties has been obtained.
Article 2 Through negotiation between both parties, the total house price payable by Party B is (RMB) only, in words (RMB). When both parties sign this contract, Party B shall pay the house price in one lump sum. At the same time, the transition fee of the house shall be owned by Party B from the date of signing the contract to the date of delivery, and Party A shall hand over the transition fee collection card to Party B on the date of signing the contract.
Party A shall issue a receipt to Party B when collecting money.
Article 3 Rights and Obligations of Party A and Party B
1. Party A shall contact Party B * * on the day of receiving the notice of repossession to handle the repossession of the house, and deliver the house to Party B for use on the day of repossession, and deliver all materials and bills related to the house to Party B. ..
2. Party A shall not sell or lease the house to others without authorization from the date of signing this contract until the property right of the house is transferred to Party B. Party A shall actively cooperate with the construction unit to handle the property right of the house, subject to the date registered on the property right certificate obtained for the first time, and cooperate with Party B to handle the transfer registration at the housing management department at the latest on the expiration of 5 years. If the transfer can be registered within 5 years, Party A shall cooperate with Party B at any time.
3. Neither Party A nor Party B shall terminate this contract without authorization.
Article 4 Cost allocation
The taxes and fees arising from Party B's purchase of the house shall be borne by Party B, and the later expenses such as Wu Tong and overhaul fund shall be paid by Party B directly to the relevant departments. Party A shall provide assistance.
Article 5 Liability for breach of contract
1. Party A must deliver the house to Party B for use on schedule, otherwise Party A shall pay Party B a penalty of 0% of the total house price for each day overdue.
2. If Party A fails to transfer the property right of the house to Party B within the time limit, or sells or rents the house to others without authorization, or Party B is unable to obtain the property right due to other reasons of Party A, Party B has the right to unilaterally terminate this contract, and demand Party A to compensate Party B for the loss at twice the market evaluation price of the house when Party B claims the right.
Article 6 Settlement of disputes in this contract
Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, either party may bring a lawsuit to the people's court where Party B is located.
Article 7 This contract is made in duplicate, one for each party and one for the witness. It shall come into force as of the date of signature and seal by both parties and have the same legal effect.
Party A (signature): Party B (signature): Witness (signature):
Year, month, year, month, year, month, day.
Article 3 of the construction agreement: Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _
According to China's Property Law, Land Management Law and other relevant laws and regulations, Party A and Party B voluntarily reach the following agreement on the purchase and sale of rural houses through full and equal consultation:
I. Both parties to this contract are _ _ _ _ _ _ _ _ collective members.
Second, the housing situation:
The house under this contract is located in _ _ _ _ _ _ _ _ _
3. The transaction house is fully funded by Party A, and the land used is _ _ _ _ _ _ group collective land, which can be occupied and used for a long time with the consent of other villagers and village collectives.
Four. Before the house is delivered to Party B, Party A guarantees that:
1. Party A has the full right to dispose of the house under this contract, or has the right to dispose of the house with the consent of other obligees;
2. Except for Party B, the house under this contract has not signed any sales agreement, compensation agreement or mortgage agreement with any third party. Party B has a relationship with a third party due to personal or family debts of Party A, or the third party has no right to enjoy the house due to court judgment;
3. If Party A violates this guarantee, Party A shall pay Party B a penalty of 30% of the total payment under this contract.
5. The knock-down price of the house under this contract is RMB _ _ _ _ _ _ _ _, including the land occupation cost of the house, the building construction cost, the value of ancillary facilities, reasonable appreciation and relevant taxes payable.
The payment of house payment by intransitive verb:
Party B shall pay all the money in one lump sum from the date when both parties sign this contract, and remit the money to Party A's account: if Party B fails to pay the house price on schedule, Party B shall pay Party A the liquidated damages for the total house price on a daily basis. If Party B fails to pay the house price within days from the date of signing this contract, Party A may terminate the contract without Party B's consent, and has the right to hold Party B liable for breach of contract.
Seven, housing delivery:
Within days from the date when Party B remits all the house payment to the account provided by Party A according to Article 6, Party A shall deliver to Party B the original house and all relevant materials including but not limited to the house homestead use right certificate and property ownership certificate, and be responsible for vacating the house; If Party A fails to deliver the materials and houses on time, it shall pay Party B RMB liquidated damages on a daily basis until Party A delivers all the materials and houses; If Party A fails to deliver the house within one month after the signing of this contract, Party B may terminate the contract without Party A's consent, and hold Party A liable for breach of contract, except for the reasons why Party B fails to pay the house price.
VIII. After receiving the written notice from Party B to handle the transfer of real estate, Party A shall actively cooperate with Party B to handle the relevant procedures for the transfer of real estate property rights according to Party B's needs; If Party A refuses or delays without reason and refuses to cooperate, Party A shall pay RMB to Party B as liquidated damages every day until assisting Party B to complete the property handover; If the transfer cannot be handled due to force majeure, policies or other reasons unrelated to Party A, Party A has nothing to do with it.
9. After the house is delivered to Party B, all rights and interests of the house (including land, house and ancillary facilities) shall be owned by Party B, including but not limited to compensation for land acquisition and demolition; If Party A receives the above compensation, it shall pay all the money to Party B. If Party A delays or refuses to pay Party B without reason, it shall pay Party B a penalty of RMB yuan in addition to all the compensation.
X. Since the delivery date of the house, all matters related to the house have nothing to do with Party A, and Party A shall not hinder or infringe upon Party B's right to possess, use and dispose of the house for any reason; Party A infringes upon Party B's rights for personal reasons (including but not limited to house sales and personal debts, etc.). , so that Party B can no longer occupy, use or dispose of the house, Party A shall, in addition to returning all the purchase price in this contract, compensate Party B according to the current market price when there is a substantial impact that prevents Party B from occupying, using or infringing Party B's right to dispose of the house.
XI。 Party A shall not sell the house to any third party without the consent of Party B from the date of signing this contract. If Party A violates this Agreement and disposes of the house without authorization, Party A shall return all the purchase price and pay liquidated damages at 100% of the total purchase price.
Twelve. Other matters:
1. Both parties have disputes over this contract, and if both parties can't solve them through negotiation, they should first request the village committee and the sub-district office to coordinate and solve them.
2. Both parties shall invite at least two members of the village collective to be the witnesses of this transaction, and sign this contract with their handprints.
3. The original of this contract is in sextuplicate, with each party holding three copies; It will take effect from the date when both parties sign and press their fingerprints, and it will remain valid.
Party A (signature and seal):
ID number:
Party B (signature and seal):
ID number:
Witness (signature and seal):
ID number:
Witness (signature and seal):
ID number:
Attached:
Witness statement
The witness stated as follows:
1. The witness and both parties are members of the collective organization;
2. There is no interest dispute between the witness and Party A or Party B in the purchase and sale of the house;
3. This contract has been witnessed by us, and both parties negotiate on an equal footing voluntarily, and there are no illegal situations such as coercion and violence, and the contract is the true intention of both parties;
4. This contract was signed at home on, 20xx, with four participants at the scene, including Party A, Party B and witnesses. The contract shall come into effect after being signed and sealed by both parties.
Witness (signature and seal):
Party A (signature and seal):
Party B (signature and seal):
20xx year month day
Article 4 of the Construction Agreement Party A: Shandong University
Party B:
According to the Contract Law of People's Republic of China (PRC) and the housing reform policy of the provincial authorities in Shandong Province, Party A and Party B have reached the following agreement on the purchase of a house in Shandong University:
1. Party A decides to raise funds to build the staff residence. Party B agrees to accept Shandong University's fund-raising housing allocation plan and voluntarily decides to participate in Shandong University's fund-raising housing construction.
2. Party A shall provide Party B with the planning scheme, building location and building type before housing allocation. Party B participates in the queuing of house selection points for raising funds to build houses according to the allocation plan of Shandong University. Residents with off-campus housing reform need property rights units to sign a housing resale agreement with Shandong University. Those who have not signed the agreement will be disqualified from queuing for housing selection. After the points are queued for publicity, Party B shall participate in the house selection according to the time and place notified by Party A. Before the house selection, Party B shall pay a deposit of 10000 yuan when receiving the Notice of Building Selection by Shandong University. Party B may give up the right to choose a house before choosing a house, but the deposit paid by Party B shall not be waived after choosing a house and being confirmed by Party A to raise funds to build a house, otherwise the deposit of 10000 yuan paid by Party B will not be refunded by Party A. After choosing a house, if Party B cannot move in due to Party A's reasons, Party A shall double the deposit to Party B.. If there is no such breach of contract, the deposit will be used as the purchase price.
3. Party A shall sign and seal the Notice of Fund Raising and Building Selection of Shandong University sent to Party B after Party B has selected the dormitory unit through fund raising. Party B shall submit the property right certificate of the original house to the school housing reform office before Party A notifies the house to be handed over. After the house selection, Party A will announce the results of the house selection, and Party A has the right to take back the house selected by the fraudster.
Four. According to the house selected by Party B, the budget price of construction area plus apportioned area is RMB. If you choose a house with an attic on the top floor, you must also pay the budget for the attic. The attic budget is temporarily paid at 60% of the house budget price, and the basement is allocated by unit and room number according to the selected building number. According to its construction area, pay the budget at 50% of the budgeted unit price of the house. The budget house payment is RMB * * *. The budget house price shall be paid in one lump sum within 10 days from the date of choosing the house. If the budget house payment is not paid in full within the time limit, or the house selection is abandoned for personal reasons, the school will allocate another house selection. Except that the deposit is not refundable, Party A will refund the advance payment paid by Party B after the housing allocation, without interest.
5. After the completion of the project, Party A will deliver to Party B the house that has passed the acceptance of the project quality supervision department .. Party B must deliver the original house to Party A within 90 days after receiving the house key, and Party B guarantees that there are no other houses and public houses except the above-mentioned houses, otherwise Party A will not handle the relevant house purchase procedures for Party B, and take back the fund-raising house selected by Party B. If Party B fails to return the selected fund-raising house on time, Party B agrees that Party A will build the fund-raising house every month after the expiration of the above 90-day period.
After the evaluation of the intransitive verb fund-raising house, the area and price of the house purchased by Party B shall be implemented according to the evaluation results determined by the Shandong Provincial Real Estate Committee Office at that time, and the area exceeding the standard shall be temporarily implemented according to the documents of the Provincial Real Estate Committee Office (XX) No.3 and Lu Zhengban (XX) No.21. Party A shall handle the house purchase and house exchange procedures for Party B in accordance with the relevant policies of housing reform in Shandong Province at that time, and the expenses incurred shall be borne by Party B. Party B shall settle the house purchase price according to the evaluation results, and refund more and make up less. After the fund-raising house purchase price is settled, Party A will issue the individual house ownership certificate to Party B. ..
7. Before Party A issues the key to the fund-raising house, if Party B is transferred from Shandong University (except for organizational arrangements) or has not returned abroad, Party A will disqualify Party B from purchasing the house, take back the fund-raising house selected by Party B, and return the budgeted house price and deposit paid by Party B without interest.
Eight, in the process of building construction, Party B shall not enter the construction site without the permission of Party A and the constructor, and shall not interfere with or affect the normal construction and management of the building. Party B can understand and supervise the whole construction process and construction quality through the school housing reform leading group and the infrastructure department.
Nine. When decorating the house, Party B shall not damage the main structure and public facilities of the house. All economic losses and related responsibilities caused by Party B's renovation shall be borne by Party B, and Party B shall bear the corresponding liability for compensation.
10. All the fund-raising houses built are subject to property management, and Party B must obey the relevant regulations and requirements of property management after moving in.
XI。 This agreement is made in triplicate, one for each party and one for the notary office. This agreement shall come into effect after being signed and sealed by both parties and applied to Shandong Notary Office for notarization, and the notarization fee shall be borne by both parties. Party A: Shandong University (seal) Party B: (signature of husband and wife)
ID number:
XX mm mm mm mm mm mm mm mm mm mm mm mm mm mm mm.
Article 5 of the House Agreement: Owner (Party A):
Contractor (Party B):
In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and the Construction Law, and in combination with the specific conditions of this project, in order to clarify the rights and obligations of Party B in the construction of Party A's private residential main project, both parties sign this contract through consultation.
I. Nature of the project
2. Pre-tender estimate of the project: Party A will build a building with a building width of () meters and a building area of () square meters.
3. Project price:
The two sides reached an agreement that the project cost per square meter is RMB (), and the total cost is tentatively RMB (), which will be settled according to the actual area.
4. Specifications of engineering materials:
1. Brick: 2. Cement:
3. strengthen: 5. Duration: from () to () year () month () day. If the construction period is extended, Party B shall pay a late fee of 5%.
6. Delivery method: When Party B enters the site, Party A pays the living expenses of RMB (). After the materials enter the site, they shall be paid according to the funds used. After the foundation comes out, pay () yuan, the first floor cover () yuan, the second floor cover () yuan, the third floor capping () yuan, the third floor capping preset thickness 10 cm.
The total house price is external powder (), internal powder () and leveling ().
Seven. Party A's responsibilities:
1.*** Party A must provide three links and one leveling when entering the site, and provide accommodation for workers.
2. During the construction, Party A shall not obstruct the construction, and shall not abuse or beat the workers. If outsiders make trouble at the construction site, Party A shall come forward to stop and mediate.
3. The project payment shall be delivered in time without delay, otherwise the lost time and loss shall be borne by Party A. After the project is completed, the project payment shall not be detained or detained.
4. Party A shall supervise the work in the ordinary house. If there are any unfinished matters, it shall negotiate with the staff in the adjacent class in time, and shall not require the handover when the work expires under any excuse. (The completed building is calculated according to the actual area).
Eight. Party B's responsibilities:
1. The quality is according to the standard of ordinary residence, and the specific construction shall be subject to the drawings of Party A.. Party A shall correct the problem in time and punish it after finding the mistake.
2. Party B's workers should live in harmony with their neighbors, do a good job in hygiene, pay attention to social impact, pay attention to construction safety, avoid disputes with the landlord, and strive to ensure quality.
Party B shall be responsible for the industrial accidents of Party B's workers during the construction period.
4. Party B's construction equipment shall be provided by Party B. ..
If there are no major quality problems after the building is completed, everything will be solved.
Nine. Liability for breach of contract:
Where Party A dismisses Party B without reason or Party B stops production without reason, both parties shall negotiate to pay liquidated damages to the other party and investigate its legal responsibilities. According to Article 107 of People's Republic of China (PRC) Contract Law:' If a party fails to perform its contractual obligations or fails to meet the contract obligations, it shall bear the liabilities for breach of contract such as continuing to perform, taking remedial measures or compensating losses.'
X. Agreed matters:
1. This contract shall come into effect on () of (), and neither party may change or terminate it without authorization.
2. This contract is made in triplicate, one for each guarantor.
Remarks: Owner (Party A): Owner (Party B): Guarantor: ID number: ID number: ID number:
Telephone: Telephone: Telephone:
After the project is completed, please pay off the project payment.
date month year
Article 6 of the Building Agreement Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
Through negotiation between Party A and Party B, Party B promises to build a civil building on the first floor of Party A, with a building area of about square meters and a total cost of RMB (in words:). After the completion acceptance, Party B shall pay according to the actual construction area. The two sides have reached the following agreement, and hope to abide by it together.
A, the foundation for the well pile foundation, * * * well pile foundation construction according to drawings, building specifications meters, * * * is divided into facade; Take the stairs indoors. The positive and negative zero points shall be determined according to the site conditions. The concrete above the bottom beam must be constructed with cement, and the wall plastering shall be constructed with 325# cement.
2. Circuit: One light bulb is inserted into each room, and the main line is 4 square copper conductor of Zhongbang and the socket line is 2.5 square copper conductor, which shall be completed by Party B. ..
Three, this project does not include painting, to ensure that water, electricity, road tee provided by Party A, construction on schedule, if there are special reasons in the construction, solved by Party A.. Party B does not assume any responsibility.
4. Through negotiation between Party A and Party B, the construction period is months (except rainy days). From the date of commencement, in order to ensure the smooth progress of the project and standardize the construction, Party A shall pay according to the project contract, and the economic losses caused by insufficient project funds shall be borne by Party A. During the construction period, Party B shall actively cooperate with Party A's reasonable suggestions to standardize the construction, and all safety accidents shall be borne by Party B. ..
5. Payment method: After negotiation between Party A and Party B, Party A shall pay Party B% of the total cost of materials,% of the total cost of the first layer of concrete before mixing,% of the total cost of the second layer of concrete before mixing,% of the total cost of the third layer of concrete before mixing,% of the total cost of exterior wall painting,% of the total cost of internal powder after finishing, and the rest shall be paid in one lump sum. Can't default on the wages of migrant workers.
Remarks on intransitive verbs:.
This agreement is made in duplicate and will come into effect after being signed.
Party A (signature): Party B (signature):
Time: time:
Article 7 of the Building Agreement Owner (Party A):
Contractor (Party B):
Party A entrusts Party B to build a two-story brick-concrete residential building. In order to clarify the rights and obligations of both parties in the construction process, the following agreement is reached through consultation:
First, the main project of private house.
Second, the construction method; Party A will contract out the main residential project to Party B in the form of contracting.
3. Construction period: the construction period is 60 days, and the commencement date is calculated from the date of signing the contract.
Four. Project price: 320 yuan in square meters.
Five, construction safety requirements and quality responsibility:
1. Party B must take strict safety protection measures in accordance with the safety construction specifications and technical requirements, pay special attention to safety construction in the construction process, put an end to all accidents, and bear the responsibility for accidents caused by inadequate or ineffective safety measures and all expenses arising therefrom.
2. Party B shall carry out the construction according to the construction operation rules, and shall not cut corners. If there are any engineering quality problems (such as the main wall is not perpendicular to the horizontal ground, the wall is uneven and cracked; The main column is not perpendicular to the horizontal ground, broken or exposed; If the cantilever beam is broken or exposed, all losses shall be borne by Party B after appraisal by relevant departments.
6. Delay in construction period: Party B shall not delay the construction period without justifiable reasons. If the completion date is delayed due to the following reasons, the construction period can be extended accordingly after being confirmed by Party A. ..
1, shut down due to power failure, rain, etc. ;
2. Force majeure;
3. Other circumstances in which Party A agrees to postpone the meeting.
Seven. Payment terms:
1. After Party B's foundation is completed, Party A shall pay off the foundation fee and pay 20,000 yuan in advance for the project.
2. After the completion of the bottom roof, if there is no quality problem, Party A will pay the project price of 20,000 yuan only.
3. After the roof pouring is completed, if there is no quality problem, Party A shall pay the project cost of 10000 Yuan only.
4. After the external wall painting is completed, if there is no quality problem, Party A will pay the project cost of 5,000 yuan.
5. After the interior wall painting is completed, if there is no quality problem, Party A will pay the project cost of 5,000 yuan only.
6. After the whole project is completed, if there is no quality problem after a rainy season next year, I will pay it in one lump sum in August.
Eight. This contract is made in duplicate and shall come into effect after being signed by both parties. After taking effect, both parties must abide by it. Matters not covered in this contract shall be settled by both parties through consultation.
Party A (signature): Party B (signature):